Alfred McAlpine v Transvaal Provincial Administration

Last updated

Alfred McAlpine & Son (Pty) Ltd v Transvaal Provincial Administration [1] is an important case in the South African law of contract, heard in the Appellate Division from 18 to 21 February 1974, and decided on 20 May. The case concerned a contract to build a portion of a national road, into which contract an exceptional number of variations was introduced. The result was disruption. Because the contract had not lapsed, the court determined that there was no new agreement in terms of which the contractor was entitled to reasonable remuneration instead of the contract price, and there was no implied term stipulating that the owner must introduce the variations "at reasonable times."

Contents

Facts

Alfred McAlpine & Son was the plaintiff, and the Transvaal Provincial Administration (TPA) the defendant, in the court a quo. The parties had entered into a contract in terms whereof the plaintiff had undertaken to build a portion of a national road. Certain declaratory orders were applied for on the plaintiff's behalf.

During the execution of the contract, the contractor had received instructions to introduce an exceptionally large number of alterations which in certain cases had caused disruption. On McAlpine's behalf, it was alleged that, although each alteration had fallen within the scope of the contract, the cumulative effect of all the alterations was of such a nature that the original contract had lapsed and a new contract arisen impliedly through the conduct of the parties. In terms of this new contract, the plaintiff was entitled to reasonable remuneration for all the work it had done: that is, from the commencement of the execution of the contract.

Tacit terms

As Corbett AJA notes in his judgment, "In legal parlance the expression 'implied term' is an ambiguous one in that it is often used, without discrimination, to denote two, possibly three, distinct concepts." [2] Terms may be implied, in other words,

  1. by operation of law (ex lege);
  2. by custom or trade usage; and
  3. from the facts surrounding the agreement of the parties (ex consensu).

The present case was concerned with whether or not that last concept should be invoked. Under South African law, a contract to do specified work for an agreed price may from its very beginning be so altered by the owner, and carried out as such by the contractor, that it may be said that for the original contract there was tacitly substituted a new agreement, in terms of which the contractor is entitled to reasonable remuneration for the work. Whether this has in fact occurred will depend on the facts.

Similarly, during the execution of a contract to do work for an agreed price, the contractor may receive, and also accept, instructions to do work which cannot really be regarded as part of the original contract. The contractor is entitled to reasonable remuneration for that work on the ground of a separate tacit agreement. This will also depend on the facts.

Judgment

The court a quo had held that the variations had been envisaged in the original contract. In an appeal, the Appellate Division found that, as the plaintiff right up to the completion of the contract had still relied on the original contract, it could not possibly be said that the original contract in its entirety had been regarded by the parties as having lapsed and that a new contract had been entered into. There was, furthermore, a lack of evidence that what the plaintiff had built was not substantially the road which the contract envisaged.

As to an alternative claim for an order declaring that a certain implied term had to be assumed, in terms whereof the plaintiff was entitled to compensation for the disruption which had occurred because the engineer had not introduced his variations "at reasonable times," the court held that "at a reasonable time" was not the same as "within a reasonable time." Such claim, the court found (Jansen JA and Corbett AJA dissenting), had rightly been rejected by the court a quo.

The decision in the Transvaal Provincial Division, in Alfred McAlpine & Son (Pty.) Ltd. v Transvaal Provincial Administration, [3] was thus confirmed. In the absence of a properly defined wording of an implied term which, notwithstanding the express provisions of the contract, had to be acknowledged, the court determined that it was not at that stage its duty to work out what wording such a term must have in order to satisfy the plaintiff as well as to comply with the stated requirements before the term could be acknowledged.

Related Research Articles

<i>Quantum meruit</i> Latin Phrase

Quantum meruit is a Latin phrase meaning "what one has earned". In the context of contract law, it means something along the lines of "reasonable value of services".

<span class="mw-page-title-main">Australian contract law</span>

The law of contract in Australia is similar to other Anglo-American common law jurisdictions.

<i>LEstrange v F Graucob Ltd</i>

L'Estrange v F Graucob Ltd [1934] 2 KB 394 is a leading English contract law case on the incorporation of terms into a contract by signature. There are exceptions to the rule that a person is bound by his or her signature, including fraud, misrepresentation and non est factum.

<span class="mw-page-title-main">Contractual term</span> Any provision forming part of a contract

A contractual term is "any provision forming part of a contract". Each term gives rise to a contractual obligation, the breach of which may give rise to litigation. Not all terms are stated expressly and some terms carry less legal gravity as they are peripheral to the objectives of the contract.

Contractual terms in English law is a topic which deals with four main issues.

<span class="mw-page-title-main">United States contract law</span>

Contract law regulates the obligations established by agreement, whether express or implied, between private parties in the United States. The law of contracts varies from state to state; there is nationwide federal contract law in certain areas, such as contracts entered into pursuant to Federal Reclamation Law.

<i>Liverpool City Council v Irwin</i>

Liverpool City Council v Irwin [1976] UKHL 1 is a leading English contract law case concerning the basis on which courts may imply terms into contracts; in particular in relation to all types of tenancies, a term may be implied if required for a particular relationship, such as for the landlord to keep the stairwells clear in a tower block. The tenants also had a duty of reasonable care which some among them had been repeatedly breached and led to a continuing breach in matters of damage about which they complained so they were not entitled to withhold rent on the facts.

In English law, implied terms are default rules for contracts on points where the terms which contracting parties expressly choose are silent, or mandatory rules which operate to override terms that the parties may have themselves chosen. The purpose of implied terms is often to supplement a contractual agreement in the interest of making the deal effective for the purpose of business, to achieve fairness between the parties or to relieve hardship.

<i>Davis Contractors Ltd v Fareham UDC</i>

Davis Contractors Ltd v Fareham Urban District Council [1956] UKHL 3 is an English contract law case, concerning the frustration of an agreement.

<i>Johnstone v Bloomsbury HA</i>

Johnstone v Bloomsbury Health Authority [1992] QB 333 is an English contract law case, concerning implied terms and unfair terms under the Unfair Contract Terms Act 1977.

<span class="mw-page-title-main">South African contract law</span> Law about agreements between two or more parties

South African contract law is "essentially a modernized version of the Roman-Dutch law of contract", and is rooted in canon and Roman laws. In the broadest definition, a contract is an agreement two or more parties enter into with the serious intention of creating a legal obligation. Contract law provides a legal framework within which persons can transact business and exchange resources, secure in the knowledge that the law will uphold their agreements and, if necessary, enforce them. The law of contract underpins private enterprise in South Africa and regulates it in the interest of fair dealing.

South African labour law regulates the relationship between employers, employees and trade unions in the Republic of South Africa.

Truter and Another v Deysel is an important case in South African law, with particular resonance in the area of civil procedure and medical malpractice. It is also frequently quoted or invoked for its definition of "cause of action." It was heard in the Supreme Court of Appeal by Harms JA, Zulman JA, Navsa JA, Mthiyane JA and Van Heerden JA on 24 February 2006; judgment was delivered on 17 March. Counsel for the appellants was JG Dickerson SC; AC Oosthuizen SC appeared for the respondent. The case was an appeal from a decision in the Cape Provincial Division by Mlonzi AJ.

Kragga Kamma Estates CC and Another v Flanagan is an important case in the South African law of contract, an appeal from a decision in the South Eastern Cape Local Division by Jansen J. It was heard in the Appellate Division on August 19, 1994, with judgement handed down on September 29. The presiding officers were EM Grosskopf JA, Nestadt JA, Kumleben JA, Howie JA and Nicholas AJA. The appellants' attorneys were Tobie Oosthuizen, Port Elizabeth, and Webbers, Bloemfontein. The respondent's attorneys were Jankelowitz, Kerbel & Schärges, Port Elizabeth, and Lovius-Block, Bloemfontein. HJ van der Linde appeared for the appellants; JRG Buchanan SC for the respondent.

Murray v Minister of Defence is an important case in South African labour law. An appeal from a decision in the Cape Provincial Division by Yekiso J, it was heard in the Supreme Court of Appeal (SCA) on 18 February 2008. Mpati DP, Cameron JA, Mlambo JA, Combrinck JA and Cachalia JA presided, handing down judgment on 31 March. Counsel for the appellant was KPCO von Lieres und Wilkau SC ; NJ Treurnicht SC appeared for the respondent. The appellant's attorneys were Van der Spuy Attorneys, Cape Town, and Hill McHardy & Herbst Ing, Bloemfontein. The respondent was represented by the State Attorney, Cape Town, and the State Attorney, Bloemfontein.

In Sweets from Heaven (Pty) Ltd and Another v Ster Kinekor Films (Pty) Ltd and Another, an important case in the South African law of lease, Ster Kinekor was a lessee which had entered into a five-year sublease with Sweets from Heaven. The second respondent was a franchise of the first applicant and occupied the premises through first applicant with the consent of Numetro.

The law of agency in South Africa regulates the performance of a juristic act on behalf or in the name of one person by another, who is authorised by the principal to act, with the result that a legal tie arises between the principal and a third party, which creates, alters or discharges legal relations between the principal and a third party. Kerr states that, in legal contexts, the word "agent" is most commonly used of a person whose activities are concerned with the formation, variation or termination of contractual obligations, and that agency has a corresponding meaning. It is the agent's position as the principal's authorised representative in affecting the principal's legal relations with third parties that is the essence of agency.

In Langley Fox Building Partnership (Pty) Ltd v De Valence, an important case in South African law, the Supreme Court of Appeal once more affirmed that a duty cast upon a defendant might be such that it is discharged only if reasonable precautions to avoid the harm are actually taken, and that the defendant who appoints another to take those steps, and fails to do so, will be liable for the failure, although it was careful to emphasise that Stratford ACJ did not purport to say that "there might be liability as an invariable rule whenever the work entails danger to the public." Goldstone AJA said that "the correct approach to the liability of an employer for the negligence of an independent contractor is to apply the fundamental rule that obliges a person to exercise that degree of care which the circumstances demand."

<i>Commonwealth Bank of Australia v Barker</i> Judgement of the High Court of Australia

Commonwealth Bank of Australia v Barker is a leading Australian judgment of the High Court which unanimously and firmly rejected the proposition that contracts of employment in Australia should contain an implied term of mutual trust and confidence.

<i>Codelfa Construction Pty Ltd v State Rail Authority of NSW</i> Judgement of the High Court of Australia

Codelfa Construction Pty Ltd v State Rail Authority of New South Wales, ("Codelfa") is a widely cited Australian contract law case, which serves as authority for the modern approach to contractual construction. The case greatly influenced the development of the Eastern Suburbs railway line. In terms of contract law, the case addresses questions of frustration, construction and the parol evidence rule. The case diverged from the well established English approach regarding the use of extrinsic evidence in contractual interpretation.

References

Books

Cases

Notes

  1. 1974 (3) SA 506 (A).
  2. 531D.
  3. 1973 (4) SA 495 (T).